SC: Appeal U/S 374 CrPC/415 BNSS is Not Maintainable Against Sessions Court's Reversal of Acquittal  ||  SC Asked the Centre to Promote Awareness About the Consequences of Driving With an Expired Licence  ||  SC Explains How a Deceased Christian Wife's Property Devolves under the Indian Succession Act  ||  Supreme Court: Reach Stacker isn't a Motor Vehicle; MACT Claim Not Maintainable  ||  Supreme Court: Lift Makers, Operators and Owners Share Responsibility for User Safety  ||  Patna HC: Pressure to Sign Divorce and Child Custody does not Amount to Cruelty  ||  Bombay HC: Externment under the Police Act Requires Satisfaction About a Gang's Activities  ||  Bombay HC: False Travel Distance Claim Alone Doesn't Constitute Misappropriation  ||  J&K&L High Court: Interest on Delayed Gratuity is Not a Mandatory Pre-Deposit For an Appeal  ||  Meghalaya HC: Meritorious Candidate Cannot Be Denied Admission For a Two-Minute Delay    

Gammon-OJSC Mosmetrostroy JV and Ors. v. Chennai Metro Rail Limited and Ors. - (High Court of Madras) (08 Sep 2015)

CMRL’s invocation of Gammon’s guarantee would cause irretrievable injustice

MANU/TN/2876/2015

Commercial

The Madras High Court granted an injunction in favour of Gammon, preventing Chennai Metro Rail Limited from invoking its bank guarantee. CMRL’s move stemmed from Gammon’s intention to rope in an Italian firm to help complete the project within the stipulated timeframe. The Court dismissed allegations that such an act was fraudulent, noting that Gammon had faced several lengthy delays arising out of operational and approval-related causes. It viewed efforts to bring in a third-party contractor as a bona fide move to completing the project in time.

Relevant : Hindustan Construction Co. Ltd. vs State of Bihar MANU/SC/0654/1999 The Godhra Electricity Co. Ltd., vs The State of Gujarat MANU/SC/0282/1974 Bishundeo Narain vs Seogeni Rai MANU/SC/0059/1951

Tags : FRAUD   GUARANTEE   METRO   INJUNCTION  

Share :        

Disclaimer | Copyright 2026 - All Rights Reserved