SC: Menstrual Health is a Fundamental Right under Article 21; Orders Free Sanitary Pads in Schools  ||  Supreme Court: Industrial Court is the Proper Forum to Decide Issues Relating to Contract Labour  ||  Supreme Court: Only Civil Court of Original Jurisdiction Can Extend Arbitral Tribunal’s Mandate  ||  SC: Demolition of Private Property Must Rest on Clear Statutory Grounds and Due Consideration  ||  SC: After Complaint Was Withdrawn, BCI Disciplinary Committee Could Not Penalise Advocate  ||  MP HC: Decree Holder Cannot Defeat Compromise or Initiate Execution by Refusing Debtor’s Cheque  ||  MP HC: Spouse’s Income Cannot Be Clubbed With Public Servant’s for Disproportionate Assets Case  ||  Ker HC: Bar Association is Not Employer & Cannot Form Internal Complaints Committee under POSH Act  ||  SC: Ex-Contract Workers Must Be Preferred When Employers Replace Contract Labour With Regular Staff  ||  SC: Waqf Tribunals Cannot Hear Claims over Properties Not Listed or Registered under Waqf Act    

Gammon-OJSC Mosmetrostroy JV and Ors. v. Chennai Metro Rail Limited and Ors. - (High Court of Madras) (08 Sep 2015)

CMRL’s invocation of Gammon’s guarantee would cause irretrievable injustice

MANU/TN/2876/2015

Commercial

The Madras High Court granted an injunction in favour of Gammon, preventing Chennai Metro Rail Limited from invoking its bank guarantee. CMRL’s move stemmed from Gammon’s intention to rope in an Italian firm to help complete the project within the stipulated timeframe. The Court dismissed allegations that such an act was fraudulent, noting that Gammon had faced several lengthy delays arising out of operational and approval-related causes. It viewed efforts to bring in a third-party contractor as a bona fide move to completing the project in time.

Relevant : Hindustan Construction Co. Ltd. vs State of Bihar MANU/SC/0654/1999 The Godhra Electricity Co. Ltd., vs The State of Gujarat MANU/SC/0282/1974 Bishundeo Narain vs Seogeni Rai MANU/SC/0059/1951

Tags : FRAUD   GUARANTEE   METRO   INJUNCTION  

Share :        

Disclaimer | Copyright 2026 - All Rights Reserved